Terms & Conditions
Last updated: May 11, 2026
These Terms and Conditions (the "Terms") constitute a legally binding agreement between you ("You," "User," or "Visitor") and Atlantic Pacific Renovations, LLC, a Georgia limited liability company ("Atlantic Pacific Renovations," "Contractor," "Company," "we," "us," or "our"). These Terms govern your access to and use of the website located at https://atlanticpacificrenovations.com (the "Site") and any related services, communications, scheduling tools, or interactions offered by the Company. By accessing or using the Site or Services, you acknowledge that you have read, understood, and agree to be bound by these Terms. If you do not agree, you must not access the Site or use the Services.
1. Use of the Site
The Site and its content are provided solely for informational purposes and to allow users to request information, consultations, estimates, or appointments. You agree to use the Site only for lawful purposes and in compliance with these Terms. You shall not misuse the Site, interfere with its operation, attempt unauthorized access, or transmit harmful, deceptive, or unlawful content.
2. User Representations & Responsibilities
By submitting information through the Site or otherwise interacting with the Services, you represent and warrant that all information you provide is truthful, accurate, current, and complete; that you are authorized to provide any information submitted; that you will not impersonate any person or entity or misrepresent your affiliation; and that you will not attempt to disrupt, damage, or impair the Site or Services.
3. Scheduling, Estimates & No Obligation
All appointment requests, consultations, walkthroughs, estimates, or inquiries submitted through the Site are requests only and do not constitute acceptance or formation of a contract. Pricing, scope of work, materials, timelines, availability, and outcomes are subject to review and written confirmation by the Company. No binding agreement exists unless and until a written contract or estimate is executed by both parties.
Any images, videos, renderings, descriptions, examples of work, pricing references, or project depictions displayed on the Site are provided for illustrative purposes only and do not constitute representations, warranties, guarantees, or assurances regarding cost, scope, materials, timelines, or results.
All Estimates expire thirty (30) days from issuance unless accepted in writing prior to expiration.
4. Agreement & Acceptance of Estimates
Atlantic Pacific Renovations, LLC issues all Estimates based solely upon the written scope of work expressly described therein. No prior discussions, representations, drawings, or communications shall modify the scope unless incorporated into a written change order executed by both parties. Any labor, materials, services, upgrades, code requirements, concealed conditions, or site circumstances not expressly included are excluded.
Acceptance of an Estimate by signature, electronic approval, written confirmation, payment of deposit, or authorization to commence work shall constitute full assent to these Terms and shall create a legally binding agreement enforceable under the laws of the State of Georgia.
5. Change Orders & Concealed Conditions
The discovery of latent or pre-existing conditions, including but not limited to structural deficiencies, framing defects, plumbing, electrical, HVAC, moisture intrusion, or code compliance issues, shall constitute a change in conditions entitling Contractor to issue a written change order for additional compensation. Contractor shall have no obligation to proceed absent written approval of such change order.
6. Payment Terms
Payment shall be made pursuant to the agreed schedule. Contractor reserves the right to suspend work upon failure to timely pay any undisputed amount due. Any unpaid balance remaining three (3) days after written notice of default shall accrue interest at the rate of ten percent (10%) per annum or the maximum lawful rate permitted under Georgia law, whichever is less.
In the event of collection or enforcement proceedings, Owner agrees to pay reasonable attorney's fees and costs as authorized by O.C.G.A. Section 13-1-11 following statutory notice. Credit card payments are subject to a disclosed 3.5% processing fee.
7. Mechanic's Lien Rights
Contractor expressly reserves all rights to file and enforce a mechanic's and materialman's lien pursuant to O.C.G.A. Section 44-14-361 et seq. for unpaid labor, services, or materials furnished.
8. Warranty
Contractor warrants its workmanship for a period of one (1) year from substantial completion. This warranty is strictly limited to defects in workmanship performed directly by Contractor and excludes materials, manufacturer defects, normal wear and tear, misuse, alterations by others, acts of God, and pre-existing or structural conditions. All manufacturer warranties shall pass through to Owner. This workmanship warranty is the sole and exclusive warranty provided to the extent permitted by Georgia law.
9. Communications & Electronic Consent
By providing contact information, you consent to receive communications from the Company by telephone, text message, or email regarding your inquiry, appointment, estimate, or services. Marketing communications will be sent only where you have provided express consent. Message frequency may vary. Message and data rates may apply. You may opt out of text messages at any time by replying STOP or HELP for assistance. Consent to receive communications is not a condition of purchase or receipt of services.
10. SMS/Text Messaging Terms
By providing your phone number and checking the SMS opt-in box, you consent to receive recurring text messages from Atlantic Pacific Renovations related to appointment reminders, project updates, estimates, service notifications, and promotional communications if separately authorized. Message frequency may vary. Message and data rates may apply. Reply STOP to cancel at any time. Reply HELP for assistance. Consent to receive SMS communications is not a condition of purchase or receipt of services.
For assistance, contact us at (470) 942-5086 or atlanticpacificrenovations@gmail.com.
Mobile phone numbers collected for SMS communications will not be shared with third parties or affiliates for marketing or promotional purposes. We only share mobile information with service providers who assist us in delivering messaging services and who are contractually obligated to maintain confidentiality and use the information solely for service delivery purposes.
SMS consent is specific to Atlantic Pacific Renovations and is not transferable to any other entity, brand, or affiliate. The Company does not guarantee delivery, timing, or receipt of SMS messages and shall not be liable for delays, non-delivery, or failures caused by mobile carriers, network providers, or third-party service interruptions.
Carriers supported: T-Mobile, AT&T, Verizon, Sprint, and all major US carriers. Carriers are not liable for delayed or undelivered messages.
Privacy: Your phone number and personal data collected through our SMS program will not be sold, rented, or shared with third parties or affiliates for marketing purposes. See our Privacy Policy for full details on how we handle your data.
11. Intellectual Property Rights
All content on the Site, including but not limited to text, images, graphics, logos, videos, and design elements, is owned by or used with permission by Atlantic Pacific Renovations and is protected by applicable intellectual property laws. You may not copy, reproduce, distribute, modify, or create derivative works without the Company's prior written consent.
12. Third-Party Websites & Services
The Site may contain links to third-party websites or services for convenience only. The Company does not control and is not responsible for the content, policies, or practices of third parties. Your use of third-party sites is at your own risk.
13. Privacy Policy
Your use of the Site and Services is subject to the Company's Privacy Policy, which is incorporated herein by reference. By using the Site, you consent to the collection, use, and disclosure of information as described in the Privacy Policy.
14. Disclaimer of Warranties
The Site and Services are provided on an "as is" and "as available" basis. To the fullest extent permitted by law, the Company disclaims all warranties, express or implied, including but not limited to implied warranties of merchantability, fitness for a particular purpose, and non-infringement. Information provided on the Site does not constitute professional, engineering, architectural, legal, or construction advice and should not be relied upon as such. The Company does not warrant that the Site will be uninterrupted, error-free, or secure.
15. Limitation of Liability & Waiver of Consequential Damages
To the maximum extent permitted by law, in no event shall Atlantic Pacific Renovations, its members, managers, officers, employees, or agents be liable for any indirect, incidental, consequential, special, exemplary, or punitive damages arising out of or relating to your use of the Site, Services, or electronic communications, including but not limited to SMS delivery failures, delays, filtering, blocking, data loss, or service interruptions, even if advised of the possibility of such damages.
You expressly waive any claim for consequential, incidental, or special damages related to electronic or telecommunications services.
16. Limitation of Damages Cap
To the maximum extent permitted by law, the total aggregate liability of Atlantic Pacific Renovations for any claim arising out of or relating to the Site or Services shall not exceed the greater of one hundred dollars ($100.00) or the amount paid by you, if any, for services giving rise to the claim. This limitation applies regardless of the legal theory asserted and even if a remedy fails of its essential purpose.
For claims arising under a signed project contract or estimate, Contractor's total liability shall not exceed the total amount actually paid under the applicable agreement.
17. Indemnification
You agree to defend, indemnify, and hold harmless Atlantic Pacific Renovations and its members, managers, officers, employees, and agents from and against any claims, demands, liabilities, damages, losses, and expenses, including reasonable attorneys' fees, arising out of or related to your use of the Site, violation of these Terms, or violation of any applicable law or third-party rights.
18. Mandatory Arbitration, Mediation & Waiver of Class Actions
Prior to initiating arbitration, the parties shall first attempt to resolve any dispute through good-faith mediation in the State of Georgia. If mediation is unsuccessful, any dispute, claim, or controversy arising out of or relating to these Terms, the Site, the Services, or any communications shall be resolved exclusively through final and binding arbitration administered in the State of Georgia pursuant to the Federal Arbitration Act.
You and the Company each waive the right to a trial by jury. Any claim shall be brought solely in an individual capacity and not as a plaintiff or class member in any purported class, consolidated, collective, or representative proceeding.
19. Force Majeure
The Company shall not be liable for any delay or failure to perform resulting from causes beyond its reasonable control, including but not limited to acts of God, weather conditions, natural disasters, labor shortages, material unavailability, supply chain disruptions, governmental actions, utility failures, telecommunications failures, SMS filtering or blocking by mobile carriers, internet service provider interruptions, cyberattacks, data breaches caused by third parties, platform outages, or other events outside the Company's direct control.
20. Assumption of Risk
You acknowledge and agree that use of the internet, electronic communications, and SMS technology involves inherent risks including delays, misdelivery, interception, data loss, and service interruptions. You expressly assume all such risks to the fullest extent permitted by law.
21. Statute of Limitations
Any claim or cause of action arising out of or related to the Site, Services, or these Terms must be filed within one (1) year after the event giving rise to the claim occurred, or such claim shall be permanently barred to the fullest extent permitted by law.
22. Electronic Records & Signatures
You consent to the use of electronic records, electronic communications, and electronic signatures in connection with the Site and Services. You agree that electronic agreements and notices satisfy any legal requirement that such communications be in writing. This consent is provided in accordance with the Electronic Signatures in Global and National Commerce Act (E-SIGN) and applicable Georgia law.
23. Governing Law & Venue
These Terms shall be governed by and construed in accordance with the laws of the State of Georgia, without regard to its conflict-of-laws principles. Any legal action or proceeding arising out of or relating to these Terms or the Services shall be brought exclusively in the state or federal courts located within the State of Georgia.
24. Modifications to Terms
The Company reserves the right to modify or update these Terms at any time. Changes will be effective upon posting to the Site. Your continued use of the Site or Services following such changes constitutes acceptance of the revised Terms.
25. Severability & Entire Agreement
If any provision of these Terms is held to be invalid or unenforceable, such provision shall be severed and the remaining provisions shall remain in full force and effect. These Terms constitute the entire agreement between you and the Company regarding the use of the Site and supersede all prior or contemporaneous agreements or understandings.
26. No Reliance
You acknowledge that you have not relied upon any statement, representation, warranty, or promise other than those expressly set forth in these Terms. No oral or implied statements shall modify or supplement these Terms.
27. Assignment
The Company may assign or transfer these Terms, in whole or in part, without restriction. You may not assign these Terms without the Company's prior written consent.
28. No Partnership or Agency
Nothing in these Terms shall be construed to create any partnership, joint venture, employment, or agency relationship between you and Atlantic Pacific Renovations. You have no authority to bind the Company in any manner.
29. Attorneys' Fees
In any dispute arising out of or relating to these Terms or the Services, the prevailing party shall be entitled to recover its reasonable attorneys' fees, costs, and expenses to the fullest extent permitted by law, including as authorized by O.C.G.A. Section 13-1-11 following statutory notice.
30. Equitable Relief
You acknowledge that any breach of the intellectual property or confidentiality provisions of these Terms may cause irreparable harm for which monetary damages would be inadequate, and the Company shall be entitled to seek injunctive or equitable relief in addition to any other remedies available at law.
31. Survival
The provisions of these Terms that by their nature should survive termination, including but not limited to limitations of liability, waiver of consequential damages, indemnification, assumption of risk, arbitration, class action waiver, statute of limitations, damages cap, attorneys' fees, and governing law, shall survive termination or expiration of these Terms.
32. Compliance with Federal & State Law
The Company intends to operate in full compliance with all applicable federal and state laws, including but not limited to the Telephone Consumer Protection Act (47 U.S.C. Section 227), CTIA Messaging Principles, CAN-SPAM Act, and applicable Georgia statutes. Nothing in these Terms shall be interpreted to require the Company to engage in any activity that violates applicable law.
33. Contact Information
If you have questions regarding these Terms, please contact Atlantic Pacific Renovations:
Phone: (470) 942-5086
Email: atlanticpacificrenovations@gmail.com
Service Area: West Georgia & North Metro Atlanta
Atlantic Pacific Renovations, LLC | Atlanta Metro, GA | atlanticpacificrenovations@gmail.com | (470) 942-5086